The Purchaser shall pay for free por Bearings or services in accordance with the free por's regular terms and prices in effect at the time of sale. The Company will notify the Purchaser of such terms and prices from time to time. In the event of legal proceedings to collect delinquent balances, Purchaser shall be liable for all amounts due, late fees, as well as attorneys fees and costs of collection.
No claims for shortages, efforts, or deficiencies will be allowed unless notice in writing is received by the Company within ten (10) days from receipt of goods by the Purchaser. No merchandise shall be returned to the Company unless authorized in advance by the XRB.
The Company will replace or, at its option, repair free of charge, for one year after the date of receipt, any goods which fail in normal use and service during that period due to defects in material or workmanship. Such goods must be returned to free por BEARINGS, transportation charges prepaid. No return shipments will be accepted without prior written authorization of Company. Company's obligations with respect to such replacement or repair shall not include costs of transportation, installation, adjustment or other expenses which may arise in connection with such replacement or repair.
The provisions of this Warranty shall not apply to any goods which have not been properly lubricated, subjected to misuse, improper storage conditions, damage due to negligence or accident, or which shall have been repaired or altered in any way so as, in the judgment of Company, to affect adversely their performance and reliability, nor which are used for a purpose for which they are not designed.
THE COMPANY'S AGREEMENT TO REPAIR OR REPLACE DEFECTIVE GOODS IS THE EXCLUSIVE REMEDY AND IS EXPRESSLY IN LIEU OF, AND IS HEREBY IN DISCLAIMER OF, ANY IMPLIED WARRANTIES OR MERCHANTABILITY AND/OR FITNESS FOR A PARTICULAR PURPOSE, AS WELL AS ALL OTHER EXPRESS OR IMPLIED WARRANTIES, IN LAW OR EQUITY, AND OF ALL OTHER OBLIGATIONS OR LIABILITIES ON COMPANY'S PART. COMPANY'S EXPRESS WARRANTY HEREUNDER RUNS ONLY TO PURCHASER AND PURCHASER'S IMMEDIATE BUYER AND DOES NOT EXTEND, EXPRESSLY OR BY IMPLICATION, TO ANY OTHER PERSON. COMPANY'S DISCLAIMER OF ALL IMPLIED WARRANTIES RUNS TO ALL SUBSEQUENT PURCHASERS, AND PURCHASER WILL PASS THIS DISCLAIMER ON TO ITS BUYER.5.Delays in Deliveries or Sales
free por usual delivery date is 5-30days according the quantity and specification,The Company will use its commercially reasonable efforts to ship products by the date specified in quotes, purchase orders and acknowledgements, but shall not be liable for delays due to shortages or unavailability of raw materials, or due to strikes, fire, accidents or other causes beyond the control the free por BEARING. In no event shall the Company be liable for prospective profits or special indirect or consequential damages, or any other damages whatsoever due to delays.